JAK Concrete & Excavation Pty Ltd Terms and Conditions of Trade

1. Definitions

  1. 1.1  Contractor” means JAK Concrete & Excavation Pty Ltd, its successors and assigns or any person acting on behalf of and with the authority of JAK Concrete & Excavation Pty Ltd.
  2. 1.2  Client” means the person/s or any person acting on behalf of and with the authority of the Client requesting the Contractor to provide the Works as specified in any proposal, quotation, order, invoice or other documentation, and:
    (a) if there is more than one Client, is a reference to each Client jointly and severally; and
    (b) if the Client is a part of a Trust, shall be bound in their capacity as a trustee; and
    (c) includes the Client’s executors, administrators, successors and permitted assigns.
  3. 1.3  “Works” means all Works or Materials provided by the Contractor to the Client at the Client’s request from time to time (where the context so permits the terms ‘Works’ or ‘Materials’ shall be interchangeable for the other).
  4. 1.4  “Price” means the Price payable (plus any GST where applicable) for the Works as agreed between the Contractor and the Client in accordance with clause 5 below.
  5. 1.5  “GST” means Goods and Services Tax (GST) as defined within the “A New Tax System (Goods and Services Tax) Act 1999” Cth.

2. Acceptance

  1. 2.1  The Client is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Client places an order for, or accepts, provision of any Works.
  2. 2.2  These terms and conditions may only be amended with the consent of both parties in writing, and shall prevail to the extent of any inconsistency with any other document or contract between the Client and the Contractor.
  3. 2.3  Electronic signatures shall be deemed to be accepted by either party providing that the parties have complied with Section 9 of the Electronic Transactions (Victoria) Act 2000 or any other applicable provisions of that Act or any Regulations referred to in that Act.
  4. 2.4  These terms and conditions may be meant to be read in conjunction with the Contractor’s Hire Form, and:
    (a) where the context so permits, the terms ‘Works’ or ‘Materials’ shall include any supply of Equipment, as defined therein; and (b) if there are any inconsistencies between the two documents then the terms and conditions contained therein shall prevail.

3. Errors and Omissions

  1. 3.1  The Client acknowledges and accepts that the Contractor shall, without prejudice, accept no liability in respect of any alleged or actual error(s) and/or omission(s): (a) resulting from an inadvertent mistake made by the Contractor in the formation and/or administration of this contract; and/or

    (b) contained in/omitted from any literature (hard copy and/or electronic) supplied by the Contractor in respect of the Works.

  2. 3.2  In the event such an error and/or omission occurs in accordance with clause 3.1, and is not attributable to the negligence and/or wilful misconduct of the Contractor; the Client shall not be entitled to treat this contract as repudiated nor render it invalid.

4. Change in Control

4.1 The Client shall give the Contractor not less than fourteen (14) days prior written notice of any proposed change of ownership of the Client and/or any other change in the Client’s details (including but not limited to, changes in the Client’s name, address, contact phone or fax number/s, or business practice). The Client shall be liable for any loss incurred by the Contractor as a result of the Client’s failure to comply with this clause.

5. Price and Payment

  1. 5.1  At the Contractor’s sole discretion, the Price shall be either:
    (a) as indicated on invoices provided by the Contractor to the Client in respect of Works provided; or
    (b) the Price as at the date of provision of the Works according to the Contractor
    ’s current price list; or
    (c) the Contractor’s quoted Price (subject to clause 5.2) which shall be binding upon the Contractor provided that the Client shall accept the Contractor’s quotation in writing within six (6) months.
  2. 5.2  The Contractor reserves the right to change the Price: (a) if a variation to the Materials which are to be provided is requested; or
    (b) if a variation to the Works originally scheduled (including any applicable designs, plans or specifications) is requested; or
    (c) where additional Works are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, hard rock

    barriers below the surface, iron reinforcing rods in concrete, obscured defects, latent conditions and/or foreign material, filling required, prerequisite work by any third party not being completed, change of design, poor weather conditions or limitations to accessing the site, etc.) which are only discovered on commencement of the Works; or

    (d) in the event of increases to the Contractor in the cost of labour or Materials, which are beyond the Contractor’s control.

  3. 5.3  Variations will be charged for on the basis of the Contractor’s quotation, and will be detailed in writing, and shown as variations on the Contractor’s invoice. The Client shall be required to respond to any variation submitted by the Contractor within ten (10) working days. Failure to do so will entitle the Contractor to add the cost of the variation to the Price. Payment for all variations must be made in full at the time of their completion.
  4. 5.4  At the Contractor’s sole discretion, a deposit may be required.
  5. 5.5  Time for payment for the Works being of the essence, the Price will be payable by the Client on the date/s determined by the Contractor, which may be:
    (a) on completion of the Works; or
    (b)
    by way of instalments/progress payments in accordance with the Contractor’s payment schedule;
    (a) either seven (7) or thirty (30) days following the end of the month in which an invoice is given to the Client by the Contractor;
    (b) the date specified on any invoice or other form as being the date for payment; or
    (c) failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Client by the Contractor.
  6. 5.6  Payment may be made by cash, cheque, bank cheque, electronic/on-line banking or by any other method as agreed to between the Client and the Contractor.
  7. 5.7  The Client shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Client by the Contractor nor to withhold payment of any invoice because part of that invoice is in dispute.
  8. 5.8  Unless otherwise stated the Price does not include GST. In addition to the Price the Client must pay to the Contractor an amount equal to any GST the Contractor must pay for any provision of Works by the Contractor under this contract, or any other agreement. The Client must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Client pays the Price. The Client must pay any other taxes and duties that may be applicable in addition to the Price, except where they are expressly included in the Price.

6. Provision of the Works

© Copyright EC Credit Control 1999 – 2020 # 33030

JAK Concrete & Excavation Pty Ltd Terms and Conditions of Trade

  1. 6.1  Subject to clause 6.2, it is the Contractor’s responsibility to ensure that the Works start as soon as it is reasonably possible.
  2. 6.2  The Works commencement date will be put back and/or the completion date extended by whatever time is reasonable in the event that the Contractor claims an extension of time (by giving the Client written notice) where completion is delayed by an event beyond the Contractor’s control, including but not limited to, any event under clause 22.8, or any failure by the Client to: (a) make a selection; or
    (b) have the site ready for the Works; or
    (c) notify the Contractor that the site is ready.
  3. 6.3  The Contractor may provide the Works by separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions in these terms and conditions.
  4. 6.4  Any time specified by the Contractor for delivery of the Works is an estimate only and the Contractor will not be liable for any loss or damage incurred by the Client as a result of delivery being late. However, both parties agree that they shall make every endeavour to enable the Works to be supplied at the time and place as was arranged between both parties. In the event that the Contractor is unable to supply the Works as agreed solely due to any action or inaction of the Client, then the Contractor shall be entitled to charge a reasonable fee for re-supplying the Works at a later time and date, and/or for storage of the Materials.

7. Risk

  1. 7.1  The Contractor shall maintain a contract works insurance policy, and public liability insurance of at least $5m, until the Works are completed; and: (a) it is the Clients responsibility to ensure that they are similarly insured; and

    (b) upon completion of the Works all risk for the Works shall immediately pass to the Client.

  2. 7.2  The Client acknowledges and agrees that, where the Contractor gives any advice, recommendation, information, assistance or service in relation to Works:
    (a) it is given in good faith, based on the Contractor
    s own knowledge and experience and shall be accepted without liability on the part of the

    Contractor. It shall be the responsibility of the Client to confirm the accuracy and reliability of the same in light of the use to which the Client

    makes or intends to make of the Works; and

(b) such advice or recommendations are not acted upon (including regarding the suitability of the site for the laying of concrete slabs,

foundations or similar work), then the Contractor shall require the Client (or its agent) to authorise commencement of the Works in writing. The Contractor shall not be liable in any way whatsoever for any damages or losses that occur after any subsequent commencement of the Works.

  1. 7.3  The Contractor shall not be held responsible for any damage to the Works, or delays to provision thereof, caused by outside agents. Where the Client requests the Contractor to repair such damage then the Contractor reserves the right to charge the Client for any costs incurred in rectifying such damage.
  2. 7.4  The Client acknowledges that variations of colour and texture are inherent in concrete. The Contractor shall not be liable for any loss, damages or costs howsoever arising resulting from any variation of the colour or texture between different batches of product.
  3. 7.5  The Client acknowledges that the curing time for concrete can be affected by elements such as temperature, or the weather, and as such the Contractor offers no guarantee as to the length of time the curing process will take.
  4. 7.6  Detailed drawings of any services that will be embedded in the concrete are to be provided to the Contractor prior to commencement of any works. Whilst all due care will be taken no liability will be accepted by the Contractor for damage to the services or any other element embedded in the concrete.
  5. 7.7  The Contractor gives no guarantee (expressed or implied) as to the length of time the curing process will take and/or against cracking of concrete that may occur naturally in the works such as:
    (a) hairline cracking of paving and grout; or
    (b) damage caused by contact with chemicals, solvents, oils or any other substances; or
    (c) the affects by elements such as heat exposure or wet weather conditions that prolong the curing process.
  6. 7.8  The Client acknowledges and agrees that it is their responsibility to organise and be liable for all costs associated with protecting the concrete and shall take all reasonable precautions to protect against destruction or damage by way of vandalism. In the event that the concrete is destroyed or damaged due to vandalism then the cost of re pair or replacement shall be borne by the Client.
  7. 7.9  The Contractor shall not be liable for any defect in the Works if the Client does not follow the Contractor’s recommendation to: (a) water the concrete for a periodically to limit the risk of possible cracking due to weather conditions;
    (b) no foot traffic and/or any vehicles on the concrete for a minimum of forty-eight (48) hours but preferably seven (7) days; (c) no heavy furniture to be placed on the concrete area for a minimum of twenty-four (24) hours.
  8. 7.10  The Client shall supply an area suitable for washing out the Contractor’sequipment and for depositing all unused concrete and slurry.
  9. 7.11  The Contractor shall be entitled to rely on the accuracy of any plans, specifications and other information provided by the Client. In the event that any of this information provided by the Client, and/or marking out of the proposed area by the Client, is inaccurate, then the Contractor accepts no responsibility for any loss, damages, or costs however resulting from these inaccuracies.
  10. 7.12  The Contractor is not insured to remove furniture or fittings and will not do so, nor is the Contractor licensed to move gas or electrical appliances.

8. Clients Responsibilities

  1. 8.1  The Client shall ensure that the Contractor has clear and free access to the site at all times to enable them to undertake the Works. The Contractor shall not be liable for any loss or damage to the site (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas), unless due to the negligence of the Contractor.
  2. 8.2  It is the Clients responsibility to:
    1. (a)  make the premises available on the agreed date and time, and have all areas clean and clear, to enable Works to be completed in accordance with the agreed work schedule. If the Works are interrupted by the failure of the Client to adhere to the agreed work schedule,

      any additional costs will be invoiced to the Client as an extra; and

    2. (b)  ensure that the site is clear of all equipment, motor vehicles, trampolines, Cubby houses or any encumbrances before the commencement of the Works. The Client further agrees that the failure to comply with this clause 8.2(b), will incur an hourly fee as determined by the

      Contractor for the removal of same and (when necessary) the reinstatement of same.

    3. (c)  remove all fragile items such as glassware, crockery, pot plants, furniture and ornaments. Breakages and damages are the responsibility of the Client. All care taken but no responsibility accepted by the Contractor in this regard; and
    4. (d)  ensure placement of boundary survey pegs for the dwelling and be responsible during the course of the works to re-instate any dislodged pegs. If the Client fails to comply with this clause, then the Contractor accepts no responsibility for installation decisions that need to be

      made by the Contractor in the Client’s absence.

    5. (e)  provide all environmental and safety fencing where applicable; and;
    6. (f)  at the Contractor’s sole discretion where applicable, termite protection.

© Copyright EC Credit Control 1999 – 2020 # 33030

JAK Concrete & Excavation Pty Ltd Terms and Conditions of Trade

  1. 8.3  Prior to the Contractor commencing the Works, the Client must advise the Contractor of the precise location of all underground services on the site and clearly mark the same. The underground mains and services the Client must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on the site. Whilst the Contractor will take all care to avoid damage to any underground services the Client agrees to indemnify the Contractor in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per this clause 8.3.
  2. 8.4  The Client acknowledges that, in the event asbestos or any other toxic substances are discovered at the site, it is the Client’s responsibility to ensure the safe removal of the same. The Client further agrees to indemnify the Contractor against any costs incurred by the Contractor as a consequence of such discovery. Under no circumstances will the Contractor handle removal of asbestos product.
  3. 8.5  Where the Client has supplied goods for the Contractor to complete the Works, the Client acknowledges that it accepts responsibility for the suitability of purpose, quality and any faults inherent in those goods. The Contractor shall not be responsible for any defects in the Works, or any loss or damage to the goods (or any part thereof), howsoever arising from the use of goods supplied by the Client.

9. Compliance with Laws

  1. 9.1  The Client and the Contractor shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the Works, including any occupational health and safety laws relating to building/construction sites and any other relevant safety standards or legislation.
  2. 9.2  The Client shall obtain (at the expense of the Client) all licenses and approvals that may be required for the Works.

10. Title

  1. 10.1  The Contractor and the Client agree that the Client’s obligations to the Contractor for the provision the Works shall not cease (and ownership of the Materials shall not pass) until:
    (a) the Client has paid the Contractor all amounts owing to the Contractor; and
    (b) the Client has met all other obligations due by the Client to the Contractor in respect of all contracts between the Contractor and the Client.
  2. 10.2  Receipt by the Contractor of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised and until then the Contractor’s ownership or rights in respect of the Materials, and this contract, shall continue.
  3. 10.3  It is further agreed that, until ownership of the Materials passes to the Client in accordance with clause 10.1:
    1. (a)  the Client is only a bailee of the Materials and unless the Materials have become fixtures must return the Materials to the Contractor on request.
    2. (b)  theClientholdsthebenefitoftheClient’sinsuranceoftheMaterialsontrustfortheContractorandmustpaytotheContractortheproceeds of any insurance in the event of the Materials being lost, damaged or destroyed. The production of these terms and conditions by the Contractor shall be sufficient evidence of the Contractor’s rights to receive the insurance proceeds direct from the insurer without the need for any person dealing with the Contractor to make further enquiries.
    3. (c)  unless the Materials have become fixtures the Client irrevocably authorises the Contractor to enter any premises where the Contractor believes the Materials are kept and recover possession of the Materials.
    4. (d)  the Client shall not charge or grant an encumbrance over the Materials nor grant nor otherwise give away any interest in the Materials while they remain the property of the Contractor.
    5. (e)  the Contractor may commence proceedings to recover the Price notwithstanding that ownership of the Materials has not passed to the Client.

11. Personal Property Securities Act 2009 (“PPSA”)

  1. 11.1  In this clause financing statement, financing change statement, security agreement, and security interest has the meaning given to it by the PPSA.
  2. 11.2  Upon assenting to these terms and conditions in writing the Client acknowledges and agrees that these terms and conditions constitute a security agreement for the purposes of the PPSA and creates a security interest in all Materials and any monetary obligations owed by the Client to the Contractor for Works that have previously been provided and that will be provided in the future by the Contractor to the Client.
  3. 11.3  The Client undertakes to:
    1. (a)  promptly sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which the Contractor may reasonably require to:
      (i) register a financing statement or financing change statement in relation to a security interest on the Personal Property Securities

      Register;
      (ii) registeranyotherdocumentrequiredtoberegisteredbythePPSA;or
      (iii) correct a defect in a statement referred to in clause 11.3(a)(i) or 11.3(a)(ii);

    2. (b)  indemnify, and upon demand reimburse, the Contractor for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register established by the PPSA or releasing any registration made thereby;
    3. (c)  not register a financing change statement in respect of a security interest without the prior written consent of the Contractor;
    4. (d)  not register, or permit to be registered, a financing statement or a financing change statement in relation to the Works in favour of a third party without the prior written consent of the Contractor.
  4. 11.4  The Contractor and the Client agree that sections 96, 115 and 125 of the PPSA do not apply to the security agreement created by these terms and conditions.
  5. 11.5  The Client hereby waives its rights to receive notices under sections 95, 118, 121(4), 130, 132(3)(d) and 132(4) of the PPSA.
  6. 11.6  The Client waives its rights as a grantor and/or a debtor under sections 142 and 143 of the PPSA.
  7. 11.7  Unless otherwise agreed to in writing by the Contractor, the Client waives its right to receive a verification statement in accordance with section 157 of the PPSA.
  8. 11.8  The Client shall unconditionally ratify any actions taken by the Contractor under clauses 11.3 to 11.5.
  9. 11.9  Subject to any express provisions to the contrary (including those contained in this clause 11) nothing in these terms and conditions is intended to have the effect of contracting out of any of the provisions of the PPSA.

12. Security and Charge

  1. 12.1  In consideration of the Contractor agreeing to provide Works, the Client charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Client either now or in the future, to secure the performance by the Client of its obligations under these terms and conditions (including, but not limited to, the payment of any money).
  2. 12.2  The Client indemnifies the Contractor from and against all the Contractor’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising the Contractor’s rights under this clause.
  3. 12.3  The Client irrevocably appoints the Contractor and each director of the Contractor as the Client’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 12 including, but not limited to, signing any document on the Client’s behalf.

© Copyright EC Credit Control 1999 – 2020 # 33030

JAK Concrete & Excavation Pty Ltd Terms and Conditions of Trade

13. Defects, Warranties and Returns, Competition and Consumer Act 2010 (CCA)

  1. 13.1  The Client must inspect the Works on completion and must within seven (7) days of such time notify the Contractor in writing of any evident defect/damage, error or omission, shortage in quantity, or failure to comply with the description or quotation. The Client must notify any other alleged defect in the Works as soon as reasonably possible after any such defect becomes evident. Upon such notification, the Client must allow the Contractor to inspect/review the Works provided.
  2. 13.2  Under applicable State, Territory and Commonwealth Law (including, without limitation the CCA), certain statutory implied guarantees and warranties (including, without limitation the statutory guarantees under the CCA) may be implied into these terms and conditions (Non- Excluded Guarantees).
  3. 13.3  The Contractor acknowledges that nothing in these terms and conditions purports to modify or exclude the Non-Excluded Guarantees.
  4. 13.4  Except as expressly set out in these terms and conditions or in respect of the Non-Excluded Guarantees, the Contractor makes no warranties or other representations under these terms and conditions including but not limited to the quality or suitability of the Materials/Works. The Contractor’s liability in respect of these warranties is limited to the fullest extent permitted by law.
  5. 13.5  If the Client is a consumer within the meaning of the CCA, the Contractor’s liability is limited to the extent permitted by section 64A of Schedule 2.
  6. 13.6  If the Contractor is required to rectify, re-provide, or pay the cost of re-providing the Works under this clause or the CCA, but is unable to do so, then the Contractor may refund any money the Client has paid for the Works but only to the extent that such refund shall take into account

    the value of Works which have been provided to the Client which were not defective.

  7. 13.7  If the Client is not a consumer within the meaning of the CCA, the Contractor’s liability for any defect or damage in the Works is: (a) limited to the value of any express warranty (or warranty card) provided to the Client by the Contractor at the Contractor’s sole discretion; (b) limited to any warranty to which the Contractor is entitled, if the Contractor did not manufacture the Materials;
    (c) otherwise negated absolutely.
  8. 13.8  Notwithstanding clauses 13.1 to 13.7 but subject to the CCA, the Contractor shall not be liable for any defect or damage which may be caused or partly caused by or arise as a result of:
    (a) the Client failing to properly maintain or store the Works;
    (b) the Client using the Works for any purpose other than that for which they were designed;
    (c) theClientcontinuingtousetheWorksafteranydefectbecameapparentorshouldhavebecomeapparenttoareasonablyprudentoperator or user;

    (d) interference with the Works by the Client or any third party without the Contractor’s prior approval; (e) the Client failing to follow any instructions or guidelines provided by the Contractor;
    (f) fair wear and tear, any accident, or act of God.

14. Intellectual Property

6.1 Where the Contractor has designed, drawn, written plans or a schedule of Works, or created any Materials for the Client, then the copyright in all such designs, drawings, documents, plans, schedules and Materials shall remain vested in the Contractor, and shall only be used by the Client at the Contractor’s discretion. Under no circumstances may such designs, drawings and documents be used without the express written approval of the Contractor.

  1. 14.1  The Client warrants that all designs, specifications or instructions given to the Contractor will not cause the Contractor to infringe any patent, registered design or trademark in the execution of the Client’s order and the Client agrees to indemnify the Contractor against any action taken by a third party against the Contractor in respect of any such infringement.
  2. 14.2  The Client agrees that the Contractor may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, drawings, plans or Materials which the Contractor has created for the Client, or digital media of any Works provided by the Contractor to the Client.

15. Default and Consequences of Default

  1. 15.1  Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at the Contractor’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.
  2. 15.2  If the Client owes the Contractor any money the Client shall indemnify the Contractor from and against all costs and disbursements incurred by the Contractor in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, the Contractor’s contract default fee, and bank dishonour fees).
  3. 15.3  Without prejudice to any other remedies the Contractor may have, if at any time the Client is in breach of any obligation (including those relating to payment) under these terms and conditions the Contractor may suspend or terminate the provision of Works to the Client. The Contractor will not be liable to the Client for any loss or damage the Client suffers because the Contractor has exercised its rights under this clause.
  4. 15.4  Without prejudice to the Contractor’s other remedies at law, the Contractor shall be entitled to cancel all or any part of any order of the Client which remains unfulfilled, and all amounts owing to the Contractor shall, whether or not due for payment, become immediately payable if:
    (a) any money payable to the Contractor becomes overdue, or in the Contractor
    ’s opinion the Client will be unable to make a payment when it falls due;
    1. (b)  the Client has exceeded any applicable credit limit provided by the Contractor;
    2. (c)  the Client becomes insolvent or bankrupt, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or
    3. (d)  a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Client or any asset of the Client.

16. Cancellation

  1. 16.1  Without prejudice to any other remedies the Contractor may have, if at any time the Client is in breach of any obligation (including those relating to payment) under these terms and conditions the Contractor may suspend or terminate the supply of Works to the Client. The Contractor will not be liable to the Client for any loss or damage the Client suffers because the Contractor has exercised its rights under this clause.
  2. 16.2  The Contractor may cancel any contract to which these terms and conditions apply, or cancel provision of Works at any time before the Works have commenced, by giving written notice to the Client. On giving such notice, the Contractor shall repay to the Client any sums paid in respect of the Price, less any amounts owing by the Client to the Contractor for Materials already procured. The Contractor shall not be liable for any loss or damage whatsoever arising from such cancellation.
  3. 16.3  In the event that the Client cancels this contract, or provision of the Works, the Client shall be liable for any and all loss incurred (whether direct or indirect) by the Contractor as a direct result of the cancellation (including, but not limited to, any loss of profits).

© Copyright EC Credit Control 1999 – 2020 # 33030

JAK Concrete & Excavation Pty Ltd Terms and Conditions of Trade

16.4 Cancellation of orders for Materials made to the Client’s specifications, or for non-stocklist items, will definitely not be accepted once production has commenced, or an order has been placed.

17. Privacy Act 1988

  1. 17.1  The Client agrees for the Contractor to obtain from a credit reporting body (CRB) a credit report containing personal credit information (e.g. name, address, D.O.B, occupation, previous credit applications, credit history) about the Client in relation to credit provided by the Contractor.
  2. 17.2  The Client agrees that the Contractor may exchange information about the Client with those credit providers and with related body corporates for the following purposes:
    (a) to assess an application by the Client; and/or
    (b) to notify other credit providers of a default by the Client; and/or
    (c) to exchange information with other credit providers as to the status of this credit account, where the Client is in default with other credit

    providers; and/or
    (d) to assess the creditworthiness of the Client including the Client
    ’s repayment history in the preceding two (2) years.

  3. 17.3  The Client consents to the Contractor being given a consumer credit report to collect overdue payment on commercial credit.
  4. 17.4  The Client agrees that personal credit information provided may be used and retained by the Contractor for the following purposes (and for other agreed purposes or required by):
    (a) the provision of Works; and/or
    (b) analysing, verifying and/or checking the Client
    ’s credit, payment and/or status in relation to the provision of Works; and/or (c) processing of any payment instructions, direct debit facilities and/or credit facilities requested by the Client; and/or
    (d) enabling the collection of amounts outstanding in relation to the Works.
  5. 17.5  The Contractor may give information about the Client to a CRB for the following purposes:
    (a) to obtain a consumer credit report;
    (b) allow the CRB to create or maintain a credit information file about the Client including credit history.
  6. 17.6  The information given to the CRB may include:
    (a) personal information as outlined in 17.1 above;
    (b) name of the credit provider and that the Contractor is a current credit provider to the Client;
    (c) whether the credit provider is a licensee;
    (d) type of consumer credit;
    (e) details concerning the Client
    ’s application for credit or commercial credit (e.g. date of commencement/termination of the credit account and the amount requested);
    (f) advice of consumer credit defaults, overdue accounts, loan repayments or outstanding monies which are overdue by more than sixty (60)

    days and for which written notice for request of payment has been made and debt recovery action commenced or alternatively that the Client no longer has any overdue accounts and the Contractor has been paid or otherwise discharged and all details surrounding that discharge (e.g. dates of payments);

    (g) information that, in the opinion of the Contractor, the Client has committed a serious credit infringement;

    (h) advice that the amount of the Client’s overdue payment is equal to or more than one hundred and fifty dollars ($150).

  7. 17.7  The Client shall have the right to request (by e-mail) from the Contractor: (a) a copy of the information about the Client retained by the Contractor and the right to request that the Contractor correct any incorrect information; and

    (b) that the Contractor does not disclose any personal information about the Client for the purpose of direct marketing.

  8. 17.8  The Contractor will destroy personal information upon the Client’s request (by e-mail) or if it is no longer required unless it is required in order to fulfil the obligations of this contract or is required to be maintained and/or stored in accordance with the law.
  9. 17.9  The Client can make a privacy complaint by contacting the Contractor via e-mail. The Contractor will respond to that complaint within seven (7) days of receipt and will take all reasonable steps to make a decision as to the complaint within thirty (30) days of receipt of the complaint. In the event that the Client is not satisfied with the resolution provided, the Client can make a complaint to the Information Commissioner at www.oaic.gov.au.

18. Building and Construction Industry Security of Payment Act 2002

  1. 18.1  At the Contractor’s sole discretion, if there are any disputes or claims for unpaid Materials and/or Works then the provisions of the Building and Construction Industry Security of Payment Act 2002 may apply.
  2. 18.2  Nothing in this agreement is intended to have the effect of contracting out of any applicable provisions of the Building and Construction Industry Security of Payment Act 2002 of Victoria, except to the extent permitted by the Act where applicable.

19. Dispute Resolution

19.1 If a dispute arises between the parties to this contract, then either party shall send to the other party a notice of dispute in writing adequately identifying and providing details of the dispute. Within fourteen (14) days after service of a notice of dispute, the parties shall confer at least once, to attempt to resolve the dispute. At any such conference, each party shall be represented by a person having authority to agree to a resolution of the dispute. In the event that the dispute cannot be so resolved either party may by further notice in writing delivered by hand or sent by certified mail to the other party refer such dispute to arbitration. Any arbitration shall be:

(a) referred to a single arbitrator to be nominated by the President of the Institute of Arbitrators Australia; and
(b) conducted in accordance with the Institute of Arbitrators Australia Rules for the Conduct of Commercial Arbitration.

20. Service of Notices

  1. 20.1  Any written notice given under this contract shall be deemed to have been given and received: (a) by handing the notice to the other party, in person;
    1. (b)  by leaving it at the address of the other party as stated in this contract;
    2. (c)  by sending it by registered post to the address of the other party as stated in this contract;
    3. (d)  if sent by facsimile transmission to the fax number of the other party as stated in this contract (if any), on receipt of confirmation of the transmission;

    (e) if sent by email to the other party’s last known email address.

  2. 20.2  Any notice that is posted shall be deemed to have been served, unless the contrary is shown, at the time when by the ordinary course of post, the notice would have been delivered.

21. Trusts

© Copyright EC Credit Control 1999 – 2020 # 33030

JAK Concrete & Excavation Pty Ltd Terms and Conditions of Trade

21.1 If the Client at any time upon or subsequent to entering in to the contract is acting in the capacity of trustee of any trust (Trust) then whether or not the Contractor may have notice of the Trust, the Client covenants with the Contractor as follows:

  1. (a)  the contract extends to all rights of indemnity which the Client now or subsequently may have against the Trust and the trust fund;
  2. (b)  the Client has full and complete power and authority under the Trust to enter into the contract and the provisions of the Trust do not purport to exclude or take away the right of indemnity of the Client against the Trust or the trust fund. The Client will not release the right of

    indemnity or commit any breach of trust or be a party to any other action which might prejudice that right of indemnity.

  3. (c)  The Client will not without consent in writing of the Contractor (the Contractor will not unreasonably withhold consent), cause, permit, or suffer to happen any of the following events;
    1. (i)  the removal, replacement or retirement of the Client as trustee of the Trust;
    2. (ii)  any alteration to or variation of the terms of the Trust;

    (iii) any advancement or distribution of capital of the Trust; or (iv) any resettlement of the trust property.

22. General

  1. 22.1  The failure by either party to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect that party’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.
  2. 22.2  These terms and conditions and any contract to which they apply shall be governed by the laws of Victoria, the state in which the Contractor has its principal place of business, and are subject to the jurisdiction of the Melbourne Courts in Victoria.
  3. 22.3  Subject to clause 13 the Contractor shall be under no liability whatsoever to the Client for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Client arising out of a breach by the Contractor of these terms and conditions (alternatively the Contractor’s liability shall be limited to damages which under no circumstances shall exceed the Price of the Works).
  4. 22.4  The Contractor may licence and/or assign all or any part of its rights and/or obligations under this contract without the Client’s consent.
  5. 22.5  The Client cannot licence or assign without the written approval of the Contractor.
  6. 22.6  The Contractor may elect to subcontract out any part of the Works but shall not be relieved from any liability or obligation under this contract by so doing. Furthermore, the Client agrees and understands that they have no authority to give any instruction to any of the Contractor’s sub

    contractors without the authority of the Contractor.

  7. 22.7  The Client agrees that the Contractor may amend these terms and conditions by notifying the Client in writing. These changes shall be deemed to take effect from the date on which the Client accepts such changes, or otherwise at such time as the Client makes a further request for the

    Contractor to provide Works to the Client.

  8. 22.8  Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.
  9. 22.9  Both parties warrant that they have the power to enter into this contract and have obtained all necessary authorisations to allow them to do so, they are not insolvent and that this contract creates binding and valid legal obligations on them.

© Copyright EC Credit Control 1999 – 2020 # 33030

Contact Us

LOCATION

JAK Concrete and Excavation Pty Ltd | abn : 38 603 736 250
Factory 3 / 217 Settlement Cowes
Victoria 3922

PHONE

Adam : 0423 647 805

EMAIL

admin@jakconcreteandexcavation.com.au

ONLINE

jakconcreteandexcavation.com.au

TRADING TERMS & CONDITIONS

Click to view & download

These terms are binding to all Quotations, variation and Invoices.

HOURS OF OPERATION

Monday : 7am - 5pm
Tuesday : 7am - 5pm
Wednesday : 7am - 5pm
Thursday : 7am - 5pm
Friday : 7am - 5pm
Saturday : 7am - 5pm